S.B. No. 1768

AN ACT

relating to the correction or removal of certain obsolete provisions of the Property Code.

BE IT ENACTED BY THE LEGISLATURE OF THE STATE OF TEXAS:

SECTION 1. Sections 27.001(4), (5), and (8), Property Code, are amended to read as follows:

(4) "Construction defect" [has the meaning assigned by Section 401.004 for an action to which Subtitle D, Title 16, applies and for any other action] means a matter concerning the design, construction, or repair of a new residence, of an alteration of or repair or addition to an existing residence, or of an appurtenance to a residence, on which a person has a complaint against a contractor. The term may include any physical damage to the residence, any appurtenance, or the real property on which the residence and appurtenance are affixed proximately caused by a construction defect.

(5) "Contractor":

(A) means:

(i) a builder[, as defined by Section 401.003,] contracting with an owner for the construction or repair of a new residence, for the repair or alteration of or an addition to an existing residence, or for the construction, sale, alteration, addition, or repair of an appurtenance to a new or existing residence;

(ii) any person contracting with a purchaser for the sale of a new residence constructed by or on behalf of that person; or

(iii) a person contracting with an owner or the developer of a condominium for the construction of a new residence, for an alteration of or an addition to an existing residence, for repair of a new or existing residence, or for the construction, sale, alteration, addition, or repair of an appurtenance to a new or existing residence; and

(B) includes:

(i) an owner, officer, director, shareholder, partner, or employee of the contractor; and

(ii) a risk retention group registered under Chapter 2201 [Article 21.54], Insurance Code, that insures all or any part of a contractor's liability for the cost to repair a residential construction defect.

(8) "Structural failure" [has the meaning assigned by Section 401.002 for an action to which Subtitle D, Title 16, applies and for any other action] means actual physical damage to the load-bearing portion of a residence caused by a failure of the load-bearing portion.

SECTION 2. Section 27.002(b), Property Code, is amended to read as follows:

(b) To [Except as provided by this subsection, to] the extent of conflict between this chapter and any other law, including the Deceptive Trade Practices-Consumer Protection Act (Subchapter E, Chapter 17, Business & Commerce Code) or a common law cause of action, this chapter prevails. [To the extent of conflict between this chapter and Title 16, Title 16 prevails.]

SECTION 3. Section 27.003(a), Property Code, is amended to read as follows:

(a) In an action to recover damages or other relief arising from a construction defect:

(1) a contractor is not liable for any percentage of damages caused by:

(A) negligence of a person other than the contractor or an agent, employee, or subcontractor of the contractor;

(B) failure of a person other than the contractor or an agent, employee, or subcontractor of the contractor to:

(i) take reasonable action to mitigate the damages; or

(ii) take reasonable action to maintain the residence;

(C) normal wear, tear, or deterioration;

(D) normal shrinkage due to drying or settlement of construction components within the tolerance of building standards; or

(E) the contractor's reliance on written information relating to the residence, appurtenance, or real property on which the residence and appurtenance are affixed that was obtained from official government records, if the written information was false or inaccurate and the contractor did not know and could not reasonably have known of the falsity or inaccuracy of the information; and

(2) if an assignee of the claimant or a person subrogated to the rights of a claimant fails to provide the contractor with the written notice and opportunity to inspect and offer to repair required by Section 27.004 [or fails to request state-sponsored inspection and dispute resolution under Chapter 428, if applicable,] before performing repairs, the contractor is not liable for the cost of any repairs or any percentage of damages caused by repairs made to a construction defect at the request of an assignee of the claimant or a person subrogated to the rights of a claimant by a person other than the contractor or an agent, employee, or subcontractor of the contractor.

SECTION 4. Sections 27.004(a), (b), (c), and (d), Property Code, are amended to read as follows:

(a) Before [In a claim not subject to Subtitle D, Title 16, before] the 60th day preceding the date a claimant seeking from a contractor damages or other relief arising from a construction defect initiates an action, the claimant shall give written notice by certified mail, return receipt requested, to the contractor, at the contractor's last known address, specifying in reasonable detail the construction defects that are the subject of the complaint. On the request of the contractor, the claimant shall provide to the contractor any evidence that depicts the nature and cause of the defect and the nature and extent of repairs necessary to remedy the defect, including expert reports, photographs, and videotapes, if that evidence would be discoverable under Rule 192, Texas Rules of Civil Procedure. During the 35-day period after the date the contractor receives the notice, and on the contractor's written request, the contractor shall be given a reasonable opportunity to inspect and have inspected the property that is the subject of the complaint to determine the nature and cause of the defect and the nature and extent of repairs necessary to remedy the defect. The contractor may take reasonable steps to document the defect. [In a claim subject to Subtitle D, Title 16, a contractor is entitled to make an offer of repair in accordance with Subsection (b). A claimant is not required to give written notice to a contractor under this subsection in a claim subject to Subtitle D, Title 16.]

(b) Not later than the [15th day after the date of a final, unappealable determination of a dispute under Subtitle D, Title 16, if applicable, or not later than the] 45th day after the date the contractor receives the notice under this section, [if Subtitle D, Title 16, does not apply,] the contractor may make a written offer of settlement to the claimant. The offer must be sent to the claimant at the claimant's last known address or to the claimant's attorney by certified mail, return receipt requested. The offer may include either an agreement by the contractor to repair or to have repaired by an independent contractor partially or totally at the contractor's expense or at a reduced rate to the claimant any construction defect described in the notice and shall describe in reasonable detail the kind of repairs which will be made. The repairs shall be made not later than the 45th day after the date the contractor receives written notice of acceptance of the settlement offer, unless completion is delayed by the claimant or by other events beyond the control of the contractor. If a contractor makes a written offer of settlement that the claimant considers to be unreasonable:

(1) on or before the 25th day after the date the claimant receives the offer, the claimant shall advise the contractor in writing and in reasonable detail of the reasons why the claimant considers the offer unreasonable; and

(2) not later than the 10th day after the date the contractor receives notice under Subdivision (1), the contractor may make a supplemental written offer of settlement to the claimant by sending the offer to the claimant or the claimant's attorney.

(c) If [compliance with Subtitle D, Title 16, or] the giving of the notice under Subsections (a) and (b) within the period prescribed by those subsections is impracticable because of the necessity of initiating an action at an earlier date to prevent expiration of the statute of limitations or if the complaint is asserted as a counterclaim, [compliance with Subtitle D, Title 16, or] the notice is not required. However, the action or counterclaim shall specify in reasonable detail each construction defect that is the subject of the complaint. The [If Subtitle D, Title 16, applies to the complaint, simultaneously with the filing of an action by a claimant, the claimant must submit a request under Section 428.001. If Subtitle D, Title 16, does not apply, the] inspection provided for by Subsection (a) may be made not later than the 75th day after the date of service of the suit, request for arbitration, or counterclaim on the contractor, and the offer provided for by Subsection (b) may be made not later than the [15th day after the date the state-sponsored inspection and dispute resolution process is completed, if Subtitle D, Title 16, applies, or not later than the] 60th day after the date of service[, if Subtitle D, Title 16, does not apply]. If, while an action subject to this chapter is pending, the statute of limitations for the cause of action would have expired and it is determined that the provisions of Subsection (a) were not properly followed, the action shall be abated to allow compliance with Subsections (a) and (b).

(d) The court or arbitration tribunal shall abate an action governed by this chapter if Subsection (c) does not apply and the court or tribunal, after a hearing, finds that the contractor is entitled to abatement because the claimant failed to [comply with the requirements of Subtitle D, Title 16, if applicable, failed to] provide the notice or failed to give the contractor a reasonable opportunity to inspect the property as required by Subsection (a), or failed to follow the procedures specified by Subsection (b). An action is automatically abated without the order of the court or tribunal beginning on the 11th day after the date a motion to abate is filed if the motion:

(1) is verified and alleges that the person against whom the action is pending did not receive the written notice required by Subsection (a), the person against whom the action is pending was not given a reasonable opportunity to inspect the property as required by Subsection (a), or the claimant failed to follow the procedures specified by Subsection (b) [or Subtitle D, Title 16]; and

(2) is not controverted by an affidavit filed by the claimant before the 11th day after the date on which the motion to abate is filed.

SECTION 5. Section 27.0042(b), Property Code, is amended to read as follows:

(b) A contractor may not elect to purchase the residence under Subsection (a) if[:

[(1)] the residence is more than five years old at the time an action is initiated[; or

[(2) the contractor makes such an election later than the 15th day after the date of a final, unappealable determination of a dispute under Subtitle D, Title 16, if applicable].

SECTION 6. Section 53.172, Property Code, is amended to read as follows:

Sec. 53.172. BOND REQUIREMENTS. The bond must:

(1) describe the property on which the liens are claimed;

(2) refer to each lien claimed in a manner sufficient to identify it;

(3) be in an amount that is double the amount of the liens referred to in the bond unless the total amount claimed in the liens exceeds $40,000, in which case the bond must be in an amount that is the greater of 1-1/2 times the amount of the liens or the sum of $40,000 and the amount of the liens;

(4) be payable to the parties claiming the liens;

(5) be executed by:

(A) the party filing the bond as principal; and

(B) a corporate surety authorized and admitted to do business under the law in this state and licensed by this state to execute the bond as surety, subject to Subchapter A, Chapter 3503, Insurance Code [Section 1, Chapter 87, Acts of the 56th Legislature, Regular Session, 1959 (Article 7.19-1, Vernon's Texas Insurance Code)]; and

(6) be conditioned substantially that the principal and sureties will pay to the named obligees or to their assignees the amount that the named obligees would have been entitled to recover if their claims had been proved to be valid and enforceable liens on the property.

SECTION 7. Section 74.3013(h), Property Code, is amended to read as follows:

(h) In this section, a nonprofit cooperative corporation means a cooperative corporation organized under Chapters 51 and 52, Agriculture Code, the Texas Nonprofit [Non-Profit] Corporation Law, as described by Section 1.008(d), Business Organizations Code [Act (Article 1396-1.01 et seq., Vernon's Texas Civil Statutes)], the Texas Cooperative Association Law, as described by Section 1.008(i), Business Organizations Code [Act (Article 1396-50.01, Vernon's Texas Civil Statutes)], and Chapter 161, Utilities Code.

SECTION 8. Sections 112.058(c) and (d), Property Code, are amended to read as follows:

(c) The community trust may transfer assets of the trust to a nonprofit corporation only if the nonprofit corporation is organized under the Texas Nonprofit Corporation Law, as described by Section 1.008(d), Business Organizations Code, [the Texas Non-Profit Corporation Act (Article 1396-1.01 et seq., Vernon's Texas Civil Statutes)] and organized for the same purpose as the community trust. The charter of the nonprofit corporation must describe the purpose of the corporation and the proposed use of the assets transferred using language substantially similar to the language used in the instrument creating the community trust.

(d) To transfer the assets of and terminate a community trust under this section, the governing body of the community trust must:

(1) file a petition in a probate court, county court, or district court requesting:

(A) the transfer of the assets of the trust to a nonprofit corporation established for the purpose of receiving and administering the assets of the trust; and

(B) the termination of the trust;

(2) send by first class mail to each trust settlor and each trustee of each component trust of the community trust who can be located by the exercise of reasonable diligence a copy of the governing body's petition and a notice specifying the time and place of the court-scheduled hearing on the petition; and

(3) publish once in a newspaper of general circulation in the county in which the proceeding is pending a notice that reads substantially similar to the following:

TO ALL INTERESTED PERSONS:

(NAME OF COMMUNITY TRUST) HAS FILED A PETITION IN (NAME OF COURT) OF (NAME OF COUNTY), TEXAS, REQUESTING PERMISSION TO CONVERT TO A NONPROFIT CORPORATION. IF PERMITTED TO CONVERT:

(1) THE (NAME OF COMMUNITY TRUST) WILL BE TERMINATED; AND

(2) THE ASSETS OF THE TRUST WILL BE:

(A) TRANSFERRED TO A NONPROFIT CORPORATION WITH THE SAME NAME AND CREATED FOR THE SAME PURPOSE AS THE (NAME OF COMMUNITY TRUST); AND

(B) HELD AND ADMINISTERED BY THE CORPORATION AS PROVIDED BY THE TEXAS NONPROFIT [NON-PROFIT] CORPORATION LAW [ACT (ARTICLE 1396-1.01 ET SEQ., VERNON'S TEXAS CIVIL STATUTES)].

THE PURPOSE OF THE CONVERSION IS TO ACHIEVE SAVINGS AND USE THE MONEY SAVED TO FURTHER THE PURPOSES FOR WHICH THE (NAME OF COMMUNITY TRUST) WAS CREATED.

A HEARING ON THE PETITION IS SCHEDULED ON (DATE AND TIME) AT (LOCATION OF COURT).

FOR ADDITIONAL INFORMATION, YOU MAY CONTACT THE GOVERNING BODY OF THE (NAME OF COMMUNITY TRUST) AT (ADDRESS AND TELEPHONE NUMBER) OR THE COURT.

SECTION 9. Section 202.002(b), Property Code, is amended to read as follows:

(b) This chapter does not affect the requirements of Chapter 123, Human Resources Code [the Community Homes for Disabled Persons Location Act (Article 1011n, Vernon's Texas Civil Statutes)].

SECTION 10. Section 202.003(b), Property Code, is amended to read as follows:

(b) In this subsection, "family home" is a residential home that meets the definition of and requirements applicable to a family home under Chapter 123, Human Resources Code [the Community Homes for Disabled Persons Location Act (Article 1011n, Vernon's Texas Civil Statutes)]. A dedicatory instrument or restrictive covenant may not be construed to prevent the use of property as a family home. However, any restrictive covenant that applies to property used as a family home shall be liberally construed to give effect to its purposes and intent except to the extent that the construction would restrict the use as a family home.

SECTION 11. Section 204.004(b), Property Code, is amended to read as follows:

(b) The association must be nonprofit and may be incorporated as a Texas nonprofit corporation. An unincorporated association may incorporate under the Texas Nonprofit [Non-Profit] Corporation Law, as described by Section 1.008(d), Business Organizations Code [Act (Article 1396-1.01 et seq., Vernon's Texas Civil Statutes)].

SECTION 12. Section 204.010(a), Property Code, is amended to read as follows:

(a) Unless otherwise provided by the restrictions or the association's articles of incorporation or bylaws, the property owners' association, acting through its board of directors or trustees, may:

(1) adopt and amend bylaws;

(2) adopt and amend budgets for revenues, expenditures, and reserves and collect regular assessments or special assessments for common expenses from property owners;

(3) hire and terminate managing agents and other employees, agents, and independent contractors;

(4) institute, defend, intervene in, settle, or compromise litigation or administrative proceedings on matters affecting the subdivision;

(5) make contracts and incur liabilities relating to the operation of the subdivision and the property owners' association;

(6) regulate the use, maintenance, repair, replacement, modification, and appearance of the subdivision;

(7) make additional improvements to be included as a part of the common area;

(8) grant easements, leases, licenses, and concessions through or over the common area;

(9) impose and receive payments, fees, or charges for the use, rental, or operation of the common area and for services provided to property owners;

(10) impose interest, late charges, and, if applicable, returned check charges for late payments of regular assessments or special assessments;

(11) if notice and an opportunity to be heard are given, collect reimbursement of actual attorney's fees and other reasonable costs incurred by the property owners' association relating to violations of the subdivision's restrictions or the property owners' association's bylaws and rules;

(12) charge costs to an owner's assessment account and collect the costs in any manner provided in the restrictions for the collection of assessments;

(13) adopt and amend rules regulating the collection of delinquent assessments and the application of payments;

(14) impose reasonable charges for preparing, recording, or copying amendments to the restrictions, resale certificates, or statements of unpaid assessments;

(15) purchase insurance and fidelity bonds, including directors' and officers' liability insurance, that the board considers appropriate or necessary;

(16) if the restrictions allow for an annual increase in the maximum regular assessment without a vote of the membership, assess the increase annually or accumulate and assess the increase after a number of years;

(17) subject to the requirements of the Texas Nonprofit [Non-Profit] Corporation Law, as described by Section 1.008(d), Business Organizations Code, [Act (Article 1396-1.01 et seq., Vernon's Texas Civil Statutes)] and by majority vote of its board of directors, indemnify a director or officer of the property owners' association who was, is, or may be made a named defendant or respondent in a proceeding because the person is or was a director;

(18) if the restrictions vest the architectural control authority in the property owners' association or if the authority is vested in the property owners' association under Section 204.011:

(A) implement written architectural control guidelines for its own use or record the guidelines in the real property records of the applicable county; and

(B) modify the guidelines as the needs of the subdivision change;

(19) exercise other powers conferred by the restrictions, its articles of incorporation, or its bylaws;

(20) exercise other powers that may be exercised in this state by a corporation of the same type as the property owners' association; and

(21) exercise other powers necessary and proper for the governance and operation of the property owners' association.

SECTION 13. The following provisions of the Property Code are repealed:

(1) Section 5.018;

(2) Sections 27.001(3) and (9);

(3) Section 27.004(l); and

(4) Section 27.007(c).

SECTION 14. This Act takes effect immediately if it receives a vote of two-thirds of all the members elected to each house, as provided by Section 39, Article III, Texas Constitution. If this Act does not receive the vote necessary for immediate effect, this Act takes effect September 1, 2023.

______________________________ ______________________________

President of the Senate Speaker of the House

I hereby certify that S.B. No. 1768 passed the Senate on April 20, 2023, by the following vote: Yeas 31, Nays 0.

______________________________ Secretary of the Senate

I hereby certify that S.B. No. 1768 passed the House on May 16, 2023, by the following vote: Yeas 136, Nays 6, one present not voting.

______________________________ Chief Clerk of the House

Approved:

______________________________

Date

______________________________

Governor