This website will be unavailable from Thursday, May 30, 2024 at 6:00 p.m. through Monday, June 3, 2024 at 7:00 a.m. due to data center maintenance.
Amend CSHB 2295 (house committee printing) as follows:
(1) Strike page 3, lines 5 and 6, and substitute the following:
SECTION 3. Sections 27.004(b), (c), (d), and (l), Property
Code, are amended to read as follows:
(b) Not later than the 15th day after the date of a final,
unappealable determination of a dispute under Subtitle D, Title 16,
if applicable, or not later than the 45th day after the date the
contractor receives the notice under this section, if Subtitle D,
Title 16, does not apply, the contractor may make a written offer of
settlement to the claimant. The offer must be sent to the claimant
at the claimant's last known address or to the claimant's attorney
by certified mail, return receipt requested. The offer may include
either an agreement by the contractor to repair or to have repaired
by an independent contractor partially or totally at the
contractor's expense or at a reduced rate to the claimant any
construction defect described in the notice and shall describe in
reasonable detail the kind of repairs which will be made. The
repairs shall be made not later than the 45th day after the date the
contractor receives written notice of acceptance of the settlement
offer, unless completion is delayed by the claimant or by other
events beyond the control of the contractor. [If a contractor makes
a written offer of settlement that the claimant considers to be
unreasonable:
[(1) on or before the 25th day after the date the
claimant receives the offer, the claimant shall advise the
contractor in writing and in reasonable detail of the reasons why
the claimant considers the offer unreasonable; and
[(2) not later than the 10th day after the date the
contractor receives notice under Subdivision (1), the contractor
may make a supplemental written offer of settlement to the claimant
by sending the offer to the claimant or the claimant's attorney.]
(2) On page 4, between lines 3 and 4, insert the following:
(d) The court or arbitration tribunal shall abate an action
governed by this chapter if Subsection (c) does not apply and the
court or tribunal, after a hearing, finds that the contractor is
entitled to abatement because the claimant failed to comply with
the requirements of Subtitle D, Title 16, if applicable or [,]
failed to provide the notice or failed to give the contractor a
reasonable opportunity to inspect the property as required by
Subsection (a)[, or failed to follow the procedures specified by
Subsection (b)]. An action is automatically abated without the
order of the court or tribunal beginning on the 11th day after the
date a motion to abate is filed if the motion:
(1) is verified and alleges that the person against
whom the action is pending did not receive the written notice
required by Subsection (a), the person against whom the action is
pending was not given a reasonable opportunity to inspect the
property as required by Subsection (a), or the claimant failed to
follow the procedures specified by [Subsection (b) or] Subtitle D,
Title 16; and
(2) is not controverted by an affidavit filed by the
claimant before the 11th day after the date on which the motion to
abate is filed.